CONTRACT COMPLETION DATE EXTENDED FROM AUGUST 25,2021 TO DECEMBER 23 2021 DUE TO COVID-19 MANUFACTURING DELAYS AND CLOSURES. |
YOY, INC |
General Services Administration |
February 22, 2021 |
December 23, 2021 |
$0 |
MODIFICATION PS0004 IS HEREBY ISSUED TO OBLIGATE FUNDING IN THE AMOUNT OF $22,207.87 TO EXTEND CM SERVICES FROM 02/28/2021 THROUGH 03/31/2021, DUE TO COVID-19 RELATED DELAYS. ALL OTHER TERMS AND CONDITIONS SHALL REMAIN THE SAME. |
PROCON CONSULTING LLC |
General Services Administration |
October 25, 2019 |
March 31, 2021 |
$22,208 |
HQ - 2021-JAN-15 - DUE TO COVID-19 GUIDANCE FROM HQ, PLEXIGLASS WILL BE INSTALLED ON ALL LOW PARTITION CUBICLES ON 4, 5, 9, 10 FLOORS LOCATED AT THE NORTHEASTERN DISTRICT.
NATIONAL INTEREST: COVID-19 |
LIVING GROUP LLC |
Office of the Comptroller of the Currency |
February 09, 2021 |
March 31, 2021 |
$32,029 |
COVID DELAYS AT CANOPY MANUFACTURING PLANT DUE TO LACK OF STEEL, LPOE BROWNSVILLE, TX |
TIKIGAQ CONSTRUCTION, LLC |
General Services Administration |
December 19, 2019 |
July 30, 2021 |
$0 |
EXTENDS PERIOD OF PERFORMANCE DUE TO COVID ILLNESS DELAY AT THE CENTER FOR DISEASE CONTROL SPACE AT THE FEDERAL BUILDING 500 GOLD AVE SW, ALBUQUERQUE, NM |
WEIL CONSTRUCTION, INC. |
General Services Administration |
April 28, 2020 |
February 08, 2021 |
-$7,394 |
DIGITAL TECHNOLOGIES INC. IS TO PROVIDE LABOR AND MATERIALS TO RETROFIT AND INSTALL (24) INTERVIEWING WINDOWS. ALL WORK IS TO TAKE PLACE AT THE SOCIAL SECURITY ADMINISTRATION OFFICE LOCATED AT 2005 LONG BEACH BLVD IN LONG BEACH, CA. |
DIGITAL TECHNOLOGIES, INC. |
General Services Administration |
December 28, 2020 |
August 27, 2021 |
$64,885 |
ADA ACCESSIBILITY REMODEL, NPWRC, JAMESTOWN, ND |
SCHUMACHER CONSTRUCTION, INC. |
U.S. Geological Survey |
December 11, 2019 |
May 31, 2021 |
$0 |
DESIGN BUILD REPLACE BOILERS AT ALCAN, ALASKA LPOE. MOD PA0008 IS NECESSARY FOR ADMINISTRATIVE PURPOSES TO PROCESS FINAL PAYMENT IN EASI PEGASYS SYSTEM |
JERNSTROM, ROBERT |
General Services Administration |
July 09, 2018 |
November 30, 2020 |
$0 |
MOD TO REDUCE CONTRACT AMOUNT TO DE-SCOPE OF A ROLL-A-SHADE PORTION OF THE PROJECT. |
DIGITAL TECHNOLOGIES, INC. |
General Services Administration |
November 05, 2020 |
March 30, 2021 |
-$13,841 |
RENOVATE MENS/WOMENS BTHRMS 3RD FLR B229 |
ANGELS GENERAL CONSTRUCTION, INC. |
Department of the Army |
September 20, 2019 |
February 01, 2021 |
$0 |
MODIFICATION PS0002 IS ISSUE TO INCREASED THE CONTRACT AMOUNT FOR BOND PAYMENT. ($1,894.98.) NO OTHER CHANGES. |
BLUE NOSE IT SOLUTIONS, INC. |
General Services Administration |
November 02, 2020 |
March 31, 2021 |
$1,895 |
MODIFICATION PS0001 IS ISSUE TO ADD BOND PAYMENT ($2,498.88). NO OTHER CHANGES. |
BLUE NOSE IT SOLUTIONS, INC. |
General Services Administration |
November 04, 2020 |
March 31, 2021 |
$2,499 |
MODIFICATION PS001 IS ISSUE TO INCREASED THE CONTRACT AMOUNT FOR BOND PAYMENT. ($2,498.88) NO OTHER CHANGES. |
BLUE NOSE IT SOLUTIONS, INC. |
General Services Administration |
November 04, 2020 |
March 31, 2021 |
$2,499 |
CONSTRUCTION SERVICES TO DESIGN AND BUILD A FUEL TRUCK STORAGE COVER WITH INTERIOR FENCE AT USCG AIR STATION SITKA, ALASKA. PERFORMANCE PERIOD EXTENDED DUE TO COVID CAUSED DELAYS 01/13/2020-07/29/2021. |
KLR NORTHERN JV |
U.S. Coast Guard |
January 13, 2020 |
July 29, 2021 |
$0 |
MODIFICATION PS0001 IS ISSUED TO INCREASED CONTRACT AMOUNT BY $823.81 FOR BOND PAYMENT. NO OTHER CHANGES. |
DIGITAL TECHNOLOGIES, INC. |
General Services Administration |
November 04, 2020 |
March 30, 2021 |
$824 |
MODIFICATION PS0001 IS ISSUED TO INCREASED CONTRACT AMOUNT BY $1,451.33 FOR BOND PAYMENT. NO OTHER CHANGES. |
DIGITAL TECHNOLOGIES, INC. |
General Services Administration |
November 09, 2020 |
March 31, 2021 |
$1,451 |
EXERCISE OPTION I AND CHANGING THE COMPLETION DATE |
KING & GEORGE, LLC |
General Services Administration |
March 01, 2020 |
November 30, 2029 |
$1,771,426 |
MOD PS0009 ISSUED TO RE-START THE CONTRACT DUE TO COVID-19 SHUTDOWN AT 8930 WARD PARKWAY, FEDERAL BUILDING, KANSAS CITY MO. |
FIRELAKE CONSTRUCTION, INC. |
General Services Administration |
September 04, 2018 |
January 08, 2021 |
$32,481 |
CONTRACTOR TO RETROFIT ROXBURY WINDOWS FOR SSA, AT 27200 TOURNEY ROAD, VALENCIA, CA. |
DIGITAL TECHNOLOGIES, INC. |
General Services Administration |
November 09, 2020 |
March 31, 2021 |
$80,629 |
CONTRACTOR TO RETROFIT 25 INTERVIEWING WINDOWS FOR SSA, 2000 OUTLET CENTER DR., OXNARD, CA |
DIGITAL TECHNOLOGIES, INC. |
General Services Administration |
November 05, 2020 |
March 30, 2021 |
$110,819 |
CONTRACTOR TO RETROFIT INTERVIEWING WINDOWS FOR SSA LOCATED AT VENTURA, CA |
OCS CONSTRUCTION SERVICES, INC. |
General Services Administration |
November 05, 2020 |
March 30, 2021 |
$49,927 |
CONTRACTOR TO RETROFIT 23 INTERVIEWING WINDOWS FOR SSA, SAN LUIS OBISPO. |
OCS CONSTRUCTION SERVICES, INC. |
General Services Administration |
November 05, 2020 |
March 30, 2021 |
$43,478 |
MODIFICATION PA0001 IS ISSUED TO CHANGED EMERGENCY ACQUISITION TO PRESIDENTIAL ISSUED EMERGENCY DECLARATION. NO OTHER CHANGES. |
BLUE NOSE IT SOLUTIONS, INC. |
General Services Administration |
November 02, 2020 |
March 31, 2021 |
$0 |
CONTRACTOR TO RETROFIT 23 INTERVIEWING WINDOWS FOR SSA 2436 PROFESSIONAL PKWY, SANTA MARIA, CA |
OCS CONSTRUCTION SERVICES, INC. |
General Services Administration |
November 05, 2020 |
March 30, 2021 |
$49,550 |
CONTRACTOR TO RETROFIT ROXBURY WINDOWS FOR SSA, AT 322 E. THOUSAND OAKS BLVD., THOUSAND OAKS, CA. |
DIGITAL TECHNOLOGIES, INC. |
General Services Administration |
November 04, 2020 |
March 30, 2021 |
$45,767 |
CONTRACTOR TO RETROFIT 23 INTERVIEWING WINDOWS FOR SSA, AT 20439 NORDHOFF ST CHATSWORTH, CA 91311. |
BLUE NOSE IT SOLUTIONS, INC. |
General Services Administration |
November 04, 2020 |
March 31, 2021 |
$99,953 |
CONTRACTOR TO RETROFIT 23 INTERVIEWING WINDOWS FOR SSA AT 14500 ROSCOE BLVD LOS ANGELES, CA. |
BLUE NOSE IT SOLUTIONS, INC. |
General Services Administration |
November 04, 2020 |
March 31, 2021 |
$99,953 |
MODIFICATION PS0007 ALCAN LPOE, ALASKA BOILER AND ASSOCIATED PIPING REPLACEMENT. THIS MODIFICATION TO EXTEND THE PERIOD OF PERFORMANCE. |
JERNSTROM, ROBERT |
General Services Administration |
July 09, 2018 |
November 30, 2020 |
$0 |
PS0002 MOD INCREASES THE AMOUNT BY $8,745.00 FROM $24,231.00 TO MAKE THE TOTAL $32,976.00 EXTENDED TO FEBRUARY 23, 2021 DUE TO APPROVED APPLICATION OF BLAST FILM AND TENT FILM AFTER REMOVAL OF EXISTING FILM AND DELAYS DUE TO THE COVID-19 PANDEMIC |
BELT BUILT CONTRACTING, LLC |
General Services Administration |
January 29, 2020 |
February 28, 2021 |
$8,745 |
COVID-19 ADDITIONAL ROUTINE CLEANING FOR LOCATIONS GA0138ZZ, GA0005ZZ, GA0057ZZ, GA0012ZZ, GA0134ZZ, GA0025ZZ |
KING & GEORGE, LLC |
General Services Administration |
March 01, 2020 |
None |
$0 |
UDPDATE FPDS TO NATIONAL INTEREST ACTION: COVID-19 2020 |
FASONE CONSTRUCTION, INC. |
General Services Administration |
January 15, 2020 |
April 16, 2021 |
$0 |
INCORPORATE 228 ADDITIONAL CALENDAR DAYS.
ADDITIONAL DAYS DUE TO COVID 19. |
FASONE CONSTRUCTION, INC. |
General Services Administration |
January 15, 2020 |
April 16, 2021 |
$7,663 |
THE PURPOSE OF THIS MODIFICATION IS TO EXTEND THE PERIOD OF PERFORMANCE END DATE TO NOVEMBER 30, 2020 DUE TO A PENDING POTENTIAL EQUITABLE ADJUSTMENT. ALL OTHER TERMS AND CONDITIONS REMAIN UNCHANGED. |
KEN TILLAGE CONSTRUCTION COMPANY, LLC |
General Services Administration |
June 06, 2019 |
November 30, 2020 |
$0 |
THIS ACTION HAS BEEN ISSUED FOR COVID-19 ADDITIONAL ROUTINE CLEANING FOR THE MACON 12 FEDERAL BUILDINGS IN GA. (GA0138ZZ, GA0005ZZ, GA0057ZZ, GA0012ZZ, GA0134ZZ AND GA0025ZZ) |
KING & GEORGE, LLC |
General Services Administration |
April 01, 2020 |
November 30, 2029 |
$6,824 |
REPLACE SOLID OXIDE FUEL CELLS (SOFC) AT USCG EMERGENCY COMMUNICATION TOWER R21 NDS AT DUFFIELD PENINSULA (SE ALASKA) EXTEND DELIVERY SCHEDULE DUE TO COVID-19 DELAYS 12/11/19-08/31/2022 |
KLR NORTHERN JV |
U.S. Coast Guard |
January 13, 2020 |
July 29, 2021 |
$0 |
EMERGENCY ROOM FLOORING REPAIR |
ADVANCED SUSTAINABLE ENGINEERED SOLUTIONS LLC |
Department of Veterans Affairs |
September 23, 2019 |
October 19, 2020 |
$0 |
CONSTRUCTION SERVICES FOR MAINTENANCE&REPAIR SENIOR OFFICER QUARTERS (SOQ) BUILDING D AT USCG BASE KODIAK AK. DELIVERY SCHEDULE EXTENDED 4 MONTHS DUE TO COVID-19 EXCUSABLE DELAYS. PERFORMANCE PERIOD 12/05/2019-11/30/2020 |
JAY BRANT GENERAL CONTRACTORS, LLC |
U.S. Coast Guard |
December 05, 2019 |
November 30, 2020 |
$90,886 |
THE PURPOSE OF THIS MODIFICATION IS TO CHANGE THE PERIOD OF PERFORMANCE END DATE FOR THE BUILDOUT OF THE FOURTH AND SIXTH FLOOR OF THE HALE BOGGS FEDERAL BUILDING IN NEW ORLEANS LOUISIANA FOR THE DEPARTMENT OF HEALTH AND HUMAN SERVICES. |
TIKIGAQ CONSTRUCTION, LLC |
General Services Administration |
December 19, 2019 |
July 30, 2021 |
$0 |
NO COST EXTENSION, SEE 2437 |
VIKING ENGINEERING AND CONSTRUCTION, LLC |
General Services Administration |
January 31, 2020 |
November 17, 2020 |
$0 |
REPLACE 12 ROLL-UP FIREHOUSE DOORS AT USCG BASE KODIAK (KODIAK, ALASKA). EQUITABLE ADJUSTMENT FOR COSTS INCURRED DURING COVID-19 TRAVEL AND USCG FACILITY ACCESS RESTRICTIONS. STORAGE OF 12 NEW FIREHOUSE DOORS. DELIVERY SCHEDULE EXTENDED 4 MONTHS |
KLR NORTHERN JV |
U.S. Coast Guard |
January 13, 2020 |
July 29, 2021 |
$12,426 |
THE PURPOSE OF THIS MODIFICATION IS TO EXTEND THE PERIOD OF PERFORMANCE UNTIL SEPTEMBER 14, 2020. |
CONTINENTAL FLOORING COMPANY |
General Services Administration |
October 10, 2019 |
September 14, 2020 |
$0 |
CONSTRUCTION SERVICES TO REPLACE THE DOMESTIC PLUMBING SYSTEM (KODIAK, AK). EXTEND DELIVERY SCHEDULE DUE TO COVID-19 DELAYS TO 11/22/2019-11/12/2020 |
AHTNA ENVIRONMENTAL, INC. |
U.S. Coast Guard |
November 22, 2019 |
November 12, 2020 |
$0 |
THIS MODIFICATION WAS ISSUED FOR COVID-19 ADDITIONAL CLEANING AT THE FEDERAL BUILDINGS IN GEORGIA. |
KING & GEORGE, LLC |
General Services Administration |
March 01, 2020 |
November 30, 2029 |
$14,427 |
CONTRACT NUMBER 47PF0020C0007 CONSTRUCTION MANAGEMENT AS CONSTRUCTOR (CMC) SERVICES FOR THE 24TH FLOOR USMS RENOVATION AT THE EVERETT MCKINLEY DIRKSEN U.S. COURTHOUSE IN CHICAGO, IL. MOD. PS0004 - ADD. WORK WITHIN SCOPE DUE TO COVID-19 TIME EXT. |
FREDERICK QUINN CORPORATION, THE |
General Services Administration |
December 18, 2019 |
December 24, 2020 |
$83,220 |
EMERGENCY SERVICE TO CONVERT TEN DENTAL PATIENT EXAM ROOMS INTO ENCLOSED NEGATIVE PRESSURE EXAM ROOMS. |
SYGNOS, INC. |
Department of Veterans Affairs |
July 28, 2020 |
November 30, 2020 |
$221,474 |
ADA ACCESSIBILITY REMODEL, NPWRC, JAMESTOWN, ND |
SCHUMACHER CONSTRUCTION, INC. |
U.S. Geological Survey |
December 11, 2019 |
May 31, 2021 |
$0 |
MODIFICATION EXTENDS THE POP FROM 6/30/2020 TO 9/30/2020 AND DOES NOT ADD ADDITIONAL FUNDS. THIS TIME EXTENSIONS IS DUE TO ESCORT AVAILABILITY B/C OF BUILDING CLOSURE FOR SOCIAL DISTANCING. WORK LOCATION: 1 JUSTICE PARK DRIVE, HOUSTON, TX 77092. |
AMERICAN RENEWABLE ENERGY |
General Services Administration |
September 30, 2019 |
September 29, 2020 |
$0 |
MODIFICATION OF (9) TEMPORARY NEGATIVE PRESSURE ON ICU ROOMS. |
SYGNOS, INC. |
Department of Veterans Affairs |
July 14, 2020 |
August 14, 2020 |
$33,774 |
ELECTRICAL HOOK-UPS FOR COVID MITIGATION TRAILER WORKSPACE |
INFORMATION TECHNOLOGY SOLUTIONS, CORP. |
Bureau of Land Management |
July 06, 2020 |
July 20, 2020 |
$1,604 |
CABLE CHANGE OUT FOR CATH LAB ROOM 322-1 |
IAW CONSTRUCTION, INC. |
Department of Veterans Affairs |
June 24, 2020 |
August 31, 2020 |
$3,040 |
THIS MODIFICATION EXTENDS THE POP FROM 5/2/2020 TO 7/31/2020 AND DOES NOT ADD ADDITIONAL FUNDS TO THE BASE AWARD AMOUNT, $129,955.60, REMAINS UNCHANGED. LOCATION OF WORK IS JACK BROOKS COURTHOUSE/FB, 300 WILLOW STREET, BEAUMONT TX 77701. |
AMERICAN RENEWABLE ENERGY |
General Services Administration |
September 30, 2019 |
September 29, 2020 |
$0 |
MODIFICATION ISSUED TO PROVIDE AN 18 CALENDAR DAY TIME EXTENSION TO ADDRESS DELAYS THAT OCCURRED AS A RESULT OF A PARTIAL SUSPENSION OF WORK. SUSPENSION WAS RELATED TO ACCESS RESTRICTIONS DUE TO COVID 19. |
RAND CONSTRUCTION COMPANY |
General Services Administration |
November 08, 2018 |
September 01, 2020 |
$16,896 |
FIRE SPRINKLER UPGRADES HALE BOGGS BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA |
COASTAL FIRE PROTECTION, L.L.C. |
General Services Administration |
September 05, 2018 |
September 12, 2020 |
$0 |
BOTH OF THESE CHANGES ARE DUE TO COVID-19 DELAYING THE FURNITURE DEMOLITION (PERFORMED UNDER A SEPARATE CONTRACT) AND REQUIRING EXTRA EFFORT OF THE GENERAL CONTRACTOR TO MEET PRE-EXISTING SCHEDULE DEMANDS OF THE CUSTOMER, WHICH CANNOT BE ACCOMMODATED FOR THE DFAS 2 PROJECT PROVIDING CONSTRUCTION SERVICES AT THE MGEJ BEAN CENTER IN INDIANAPOLIS, INDIANA. |
ACCEL CONSTRUCTION SERVICES GROUP, LLC |
General Services Administration |
March 14, 2018 |
September 21, 2021 |
$30,027 |
DUBERSTEIN JANITORIAL - ADDITIONAL MONTHLY COVID-19 CLEANING |
NYSARC, INC. |
General Services Administration |
July 14, 2020 |
August 28, 2020 |
$234,246 |
COURTS REQUESTED 1940ISH TRANSOM&DOOR MATERIAL FOR THE COURTROOM WHICH TOOK LONGER THAN EXPECTED TO ACQUIRE&APPROVE. WICHITA FALLS, TX COURTHOUSE |
UNIFIED SERVICES OF TEXAS, INCORPORATED |
General Services Administration |
March 13, 2019 |
June 30, 2020 |
$4,142 |
THE PURPOSE OF THIS MODIFICATION IS TO INCORPORATE WORK DESCRIBED IN MOD 002 STATEMENT OF WORK DATED APRIL 9, 2020. |
PATTON CONTRACTORS, INC. |
General Services Administration |
December 11, 2019 |
March 31, 2021 |
$86,046 |
MODIFICATION PS0004 IS TO EXTEND PERIOD OF PERFORMANCE FROM MARCH 29, 2020 TO JULY 31, 2020, A TOTAL OF 124 DAYS DUE TO US ATTORNEY'S OFFICE BEING UNDER QUARANTINE DUE TO COVID-19 AND REMAINING SO UNTIL COVID-19 RESTRICTIONS ARE LIFTED. |
JAMCO VENTURES LLC |
General Services Administration |
September 20, 2019 |
July 31, 2020 |
$0 |
MODIFICATION PS0001 TO TASK ORDER 47PH0420F0004 IS TO EXTEND THE PERIOD OF PERFORMANCE FROM FEBRUARY 28, 2020 TO JUNE 2, 2020, A TOTAL OF 94 DAYS TO ALLOW ENOUGH TIME TO CONDUCT FINAL TESTING AND FINAL INSPECTION DUE TO COVID-19 LOCAL RESTRICTIONS. |
AMSTAR, INC. |
General Services Administration |
December 17, 2019 |
June 02, 2020 |
$0 |
COVID-19 NO COST TIME EXTENSION - CONTRACT IS INCREASED BY 27 CALENDAR DAYS. ALBUQUERQUE, NEW MEXICO. NM0030ZZ |
ROSS GROUP CONSTRUCTION CORPORATION, THE |
General Services Administration |
April 01, 2019 |
May 18, 2020 |
$0 |
45 NO COST EXTENSION PER EXCUSABLE DELAYS DUE TO COVID-19 |
VIKING ENGINEERING AND CONSTRUCTION, LLC |
General Services Administration |
January 31, 2020 |
November 17, 2020 |
$0 |
COVID-19 CONSTRUCTION SAFETY PAUSE CONTINUANCE EXTENDING THE COMPLETION DATE TO JULY 7, 2022 AT NO COST TO THE GOVERNMENT - HEBERT FEDERAL BUILDING, NEW ORLEANS, LA |
BRASFIELD & GORRIE, L.L.C. |
General Services Administration |
May 09, 2019 |
July 07, 2022 |
$0 |
DESIGN BUILD US COAST GUARD BUNKROOM REMODEL IN THE JUNEAU, ALASKA FEDERAL BUILDING MODIFICATION PS0001 IS TO EXTEND THE PERIOD OF PERFORMANCE DUE TO COVID VIRUS TRAVEL RESTRICTIONS IN ALASKA AND AGENCY'S REQUEST TO DELAY WORK. |
ORION CONSTRUCTION, INC. |
General Services Administration |
September 19, 2019 |
October 30, 2020 |
$0 |
MODIFICATION IS TO EXTEND THE PERIOD OF PERFORMANCE OF THIS CONTRACT BY 91 DAYS DUE TO GOVERNMENT DELAY ACCOMMODATE FUTURE DELAYS DUE TO PUBLIC HEALTH EMERGENCY COVID-19.
CHANGE THE PERIOD OF PERFORMANCE FROM 03/31/2020 TO 06/30/2020 AN INCREASE OF 91 CALENDAR DAYS. |
UNIFIED SERVICES OF TEXAS, INCORPORATED |
General Services Administration |
March 13, 2019 |
June 30, 2020 |
$0 |
REPAIR AND REPLACE HVAC EQUIPMENT LOCATED AT THE FDA BOTHELL LABORATORIES IN BOTHELL, WA. PS01 PROVIDES AN EXCUSABLE DELAY IN RELATION TO COVID-19. |
SAYBR CONTRACTORS, INC. |
General Services Administration |
December 26, 2019 |
August 10, 2020 |
$0 |
CONTRACTOR MUST FURNISH ALL LABOR, PARTS, MATERIALS AND EQUIPMENT FOR CARPET AND PAINT INSTALLATION FOR USDC, C-351 C-367 @ HALE BOGGS FEDERAL BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
PATTON CONSTRUCTION, INC. |
General Services Administration |
December 11, 2018 |
May 07, 2020 |
$0 |
HHS OHMA BUILDOUT @ HALE BOGGS FEDERAL BLDG, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
TIKIGAQ CONSTRUCTION, LLC |
General Services Administration |
December 19, 2019 |
July 30, 2021 |
$0 |
USMS, DESIGN BUILD PROJECT ON 7TH FLOOR @ THE BOGGS FEDERAL BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA. |
PATTON CONTRACTORS, INC. |
General Services Administration |
December 11, 2019 |
March 31, 2021 |
$0 |
USDC MAGISTRATE HALLWAYS FINISHES @ HALE BOGGS FEDERAL BLDG., 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
KEN TILLAGE CONSTRUCTION COMPANY, LLC |
General Services Administration |
June 06, 2019 |
November 30, 2020 |
$0 |
USDC SOUNDPROOFING COURTROOM RENOVATION PROJECT @ HALE BOGGS FEDERAL BLDG, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
KEN TILLAGE CONSTRUCTION COMPANY, LLC |
General Services Administration |
June 06, 2019 |
November 30, 2020 |
$0 |
USCG SCIF RENOVATION PROJECT ON 13TH FLOOR @ HALE BOGGS FEDERAL BLDG, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
TIKIGAQ CONSTRUCTION, LLC |
General Services Administration |
December 19, 2019 |
July 30, 2021 |
$0 |
FIRE SPRINKLER UPGRADES HALE BOGGS BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
COASTAL FIRE PROTECTION, L.L.C. |
General Services Administration |
September 05, 2018 |
September 12, 2020 |
$0 |
RENOVATION FOR US DISTRICT COURTS @ HALE BOGGS FEDERAL BLDG, 500 POYDRA STREET, NEW ORLEANS, LA 70130 |
PATTON CONTRACTORS, INC. |
General Services Administration |
December 11, 2019 |
March 31, 2021 |
$0 |
CYCLICAL REPLACEMENT OF CARPET IN THE USDC CLERK'S OFFICE, 1ST FLOOR, HALE BOGGS BLDG. 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
CONTINENTAL FLOORING COMPANY |
General Services Administration |
October 10, 2019 |
September 14, 2020 |
$0 |
CHANGE FUND CODE FROM 192X TO 192V |
DAI LLC |
General Services Administration |
March 25, 2020 |
April 25, 2020 |
$0 |
COVID-19 CONSTRUCTION PHASE SAFETY PAUSE, NEW ORLEANS, LA |
BRASFIELD & GORRIE, L.L.C. |
General Services Administration |
May 09, 2019 |
July 07, 2022 |
$0 |
DEEP CLEANING SERVICES COVID19 |
DAI LLC |
General Services Administration |
March 25, 2020 |
April 25, 2020 |
$26,039 |
PACIFIC HIGHWAY UPGRADE INSPECTION BOOTH, BLAINE WA. MODIFICATION FOR TIME EXTENSION FOR EXCUSABLE DELAY DUE TO COVID-19. |
RONSONS DESIGN & CONSTRUCTION, LLC |
General Services Administration |
July 03, 2019 |
June 23, 2020 |
$0 |
USDC C-351&C-367 CARPET AND PAINT, HALE BOGGS FEDERAL BLDG, NEW ORLEANS, LA |
PATTON CONSTRUCTION, INC. |
General Services Administration |
December 11, 2018 |
May 07, 2020 |
$0 |
RENOVATION PROJECT FOR USMS ON THE 10TH FLOOR @HALE BOGGS FEDERAL BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
WRIGHT BROS., LLC |
General Services Administration |
September 20, 2019 |
February 06, 2021 |
$0 |
RENOVATION PROJECT FOR USCG SCIF 0N THE 13TH FLOOR @ HALE BOGGS FEDERAL BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
TIKIGAQ CONSTRUCTION, LLC |
General Services Administration |
December 19, 2019 |
July 30, 2021 |
$0 |
RENOVATION PROJECT FOR HHS ON 4TH AND 6TH FLOOR @ HALE BOGGS FEDERAL BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
TIKIGAQ CONSTRUCTION, LLC |
General Services Administration |
December 19, 2019 |
July 30, 2021 |
$0 |
THE PURPOSE OF THIS MODIFICATION IS TO SUSPEND WORK IN ACCORDANCE WITH FAR 52.242-14, SUSPENSION OF WORK AT THE HALE BOGGS FEDERAL BUILDING LOCATED AT 500 POYDRAS STREET, NEW ORLEANS, LOUISIANA 70130. |
KEN TILLAGE CONSTRUCTION COMPANY, LLC |
General Services Administration |
June 06, 2019 |
November 30, 2020 |
$0 |
RENOVATION OF MAGISTRATE JUDGE DOUGLAS CHAMBERS @ HALE BOGGS FEDERAL BLDG, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
PATTON CONTRACTORS, INC. |
General Services Administration |
December 11, 2019 |
March 31, 2021 |
$0 |
DESIGN-BUILD RENOVATION PROJECT FOR USMS ON 7TH FLOOR @ HALE BOGGS FEDERAL BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
PATTON CONTRACTORS, INC. |
General Services Administration |
December 11, 2019 |
March 31, 2021 |
$0 |
EMERGENCY REQUEST FOR RENOVATION/BUILD BACK ON THE 1ST FLOOR @ THE HALE BOGGS FEDERAL BUILDING, 500 POYDRAS STREET, NEW ORLEANS, LA 70130 |
NATIVE ENGINEERS, LLC |
General Services Administration |
January 23, 2020 |
April 30, 2020 |
$0 |